{"id":635,"date":"1999-11-01T15:38:15","date_gmt":"1999-11-01T15:38:15","guid":{"rendered":"http:\/\/fwhtlaw.com\/?post_type=briefing-papers&p=635"},"modified":"1999-11-01T15:38:15","modified_gmt":"1999-11-01T15:38:15","slug":"coordination-multi-prime-contracts","status":"publish","type":"post","link":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/","title":{"rendered":"Coordination of Multi-Prime Contracts"},"content":{"rendered":"

Introduction<\/span><\/h1>\n

Traditionally, on large construction projects, an owner contracted with a general contractor for the construction of the entire project. The owner had a single contract with the general contractor. As a result, the owner depended entirely on the general contractor for the project\u2019s success.<\/p>\n

Rather than employ a general contractor to assume responsibility for an entire construction project, an owner might choose to divide the work by contracting directly with several contractors. This practice is commonly referred to as multi-prime contracting (a\/k\/a multiple prime, separate prime, and parallel prime).<\/p>\n

Advocates of multi-prime contracting contend that this method of project delivery promotes increased competition and participation among contractors, and results in lower costs on bid day. Opponents, however, suggest that multi-prime bidding inherently leads to management or coordination failures. Accordingly, owners often seek a construction methodology that will achieve the cost-savings of multi-prime contracting while simultaneously reaping the benefits of increased coordination and accountability.<\/p>\n

The Duty to Coordinate: Multi-Prime Projects<\/span><\/h1>\n

Although providing owners with the opportunity to reduce project time and expense, as well as increase control, multi-prime contracting also presents a number of new risks and responsibilities. To date, coordination of prime contractors remains the most significant challenge to multi-prime contracting. The coordination difficulties accompanying construction projects have not gone unnoticed by the judiciary. Nearly twenty years ago, in Blake Construction, Inc. v. C.J. Coakley Co., Inc., the court stated that:<\/p>\n

[e]xcept in the middle of a battlefield, nowhere must men coordinate the movement of other men and all materials in the midst of such chaos and with such limited certainty of present facts and future occurrences as in a huge construction project. . . .<\/p><\/blockquote>\n

Most owners lack the expertise or resources necessary to successfully embrace the incredible coordination responsibilities involved with large construction projects. Nonetheless, it is generally accepted that the duty to coordinate the prime contractors rests with the owner in multi-prime construction projects. Accordingly, knowing they can be held accountable for damages created by any number of coordination problems, owners often look to limit, share, shift, or altogether avoid their duty to coordinate.<\/p>\n

Some owners will require one or more design professionals (e.g., project architect) to supervise and coordinate the prime contractors through the designer\u2019s contractual duty to administer the contract. More recently, with the growing popularity of construction management, owners have employed a professional construction management entity (\u201cCM\u201d) to provide project management expertise. A CM can provide project coordination and supervision for the owner under either an \u201cat risk\u201d or \u201cnot at risk\u201d model. Under the \u201cat risk\u201d model, the CM (as an independent contractor) selects and contracts with the prime contractors. The \u201cat risk\u201d CM guarantees the full performance of the contract to the owner, as well as payments to the prime contractors. Conversely, when \u201cnot at risk,\u201d there is neither a contractual relationship between the CM and any of the prime contractors — nor prime contractor performance guarantees inuring to the benefit of the owner.<\/p>\n

A less popular option for owners is to shift certain coordination responsibilities to one or more of the project\u2019s prime contractors through the express language of the parties\u2019 contract. Courts, however, have been suspect of such coordination shifting contractual provisions.<\/p>\n

For example, in Shea – S & M Ball v. Massman-Kiewit-Early, the court considered whether a contractual provision had shifted an owner\u2019s coordination responsibilities to the project\u2019s prime contractors. Initially, the court acknowledged that the contracts between the owner and each prime contractor required all of the primes to cooperate with each other throughout the project. Nonetheless, the court ultimately determined that the owner retained a contractual duty to compel such cooperation when required.<\/p>\n

The Shea – S & M Ball decision highlights the practical flaw which accompanies an owner\u2019s attempt to shift all coordination responsibilities to its prime contractors. How does one prime contractor force another prime contractor to act in the absence of a contractual relationship between them? Suppose a mechanical prime contractor\u2019s ongoing delays begin to adversely impact the work schedule of the project\u2019s electrical prime contractor. The electrical contractor has no mechanism to force the mechanical contractor to accelerate or otherwise perform. The electrical contractor cannot threaten to withhold payment or terminate the mechanical contractor\u2019s contract. Without the power of the purse, the electrical contractor has no leverage to compel project coordination. As indicated, the court in Shea – S & M Ball resolved this dilemma by ruling that the owner had a continuing obligation to flex its contractual muscle to compel contractor cooperation.<\/p>\n

Measuring and Recovering the Costs of Coordination Failures<\/span><\/h1>\n

Failure to properly coordinate a construction project can severely impact the contractor. Coordination failures often require contractors to re-sequence work — leading to a marked decrease in labor productivity. As a result of the decreased labor productivity, the contractor often falls behind schedule — requiring a costly period of work acceleration. Damages attributable to both of these measurable impacts can be recovered from the owner.<\/p>\n

 <\/p>\n

Re-sequencing Work = Labor Inefficiency<\/h4>\n

Coordination problems can infect an entire project. Typically, coordination problems which adversely impact the project contractor may hinder the architect or engineer as well. For example, lagging design changes in a limited area can quickly escalate into large scale project alterations if the initial changes are not properly coordinated. Equipment and materials to be furnished by other contractors often arrive early, later, or in error. Such problems are often traced to the contractor\u2019s failure to receive accurate design and\/or scheduling information. Regardless of the type or nature of the construction coordination problem, the end result is always the same: idle and unproductive workers.<\/p>\n

Even on a small construction project, it is inevitable that the project design will include inconsistencies. Typically, contractors resolve these inconsistencies by submitting requests for clarification to the project designers. A large number of inconsistencies and\/or a slow response from the design team all but guarantees labor inefficiencies for the contractor.<\/p>\n

Consider the following example. A project consists of work in two distinct areas. The initial construction schedule contemplates that the contractor\u2019s work will be commenced and completed in the first area prior to any work in area two. This sequence, which minimizes mobilization and demobilization time, is an efficient use of labor. Suppose that halfway through area one, in the course of placing a fixture, the foreman of the contractor\u2019s work crew identifies a conflict in the project\u2019s design specifications. Further assume that work cannot proceed in the first area until the conflict is resolved.<\/p>\n

If the project had been properly coordinated, the foreman would have both identified the conflict and obtained clarification from the project designers long before the arrival of the work crew. Conversely, if the design conflict is first discovered at the project site, the foreman is left with two undesirable options. First, the foreman and the work crew can sit idly by until the design team resolves the conflict. Second, the foreman can demobilize the work crew and move it to area two of the project (and re-mobilize upon arrival). Of course, the latter option will ultimately require the work crew to return to the first area once the design conflict is resolved. As illustrated by this simplistic example, even seemingly minor coordination problems can result in significant expense for the contractor.<\/p>\n

 <\/p>\n

Re-sequencing Work = Lost $$$$<\/h4>\n

As indicated, the re-sequencing of work impedes a contractor\u2019s efficient use of labor. When bidding a job, the contractor fairly assumes that it will be able to perform its work at a reasonable progression within the parameters of the contract. For example, when an electrical contractor bids a job, it can assume that walls\/ceilings will be sufficiently completed as to allow for the installation of fixtures when it arrives at the project site. If preliminary construction is incomplete, the electrical contractor simply cannot perform its work. Electrical work crews become idle. Time is also expended reassigning work crews to other areas or projects. Additional time is expended mobilizing and demobilizing crews.<\/p>\n

Fortunately, it is possible to both capture and measure the sum impact of such re-sequencing and idle time on labor productivity. Typically, a contractor will rely on an expert in the field of construction labor productivity to quantify losses based on the project record (e.g., time cards, schedules, weather, quality of labor). The expert is ultimately able to calculate the contractor\u2019s \u201cbaseline,\u201d or standard, productivity rate (e.g., 1.0 hours of labor to install ten (10) feet of 1\u201d electrical conduit). The expert subsequently compares the baseline productivity rate with the productivity rate achieved by contractor when impacted by re-sequencing and idle time. For example, a final comparison might appear as follows:
\nExpected
\nExpected Hours<\/span>\u00a0\u00a0\u00a0\u00a0\u00a0Units of Production<\/span>
\n100\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0 500 ft. 1\u201d electrical conduit<\/p>\n

 <\/p>\n

Actual Units
\nActual Hours<\/span>\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0of Production<\/span><\/p>\n

100\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0 250 ft. 1\u201d electrical conduit<\/p>\n

 <\/p>\n

In this oversimplified illustration, the expert has determined that re-sequencing and idle time cut the contractor\u2019s labor productivity rate in half. Of course, a labor productivity expert\u2019s calculations will always need to account for overtime, change orders, weather, learning curves, project characteristics affecting labor, and project management. By eliminating all project impacts unrelated to re-sequencing and idle time from the bottom line, the expert is able to fully and accurately identify the extent of the owner\u2019s financial responsibility.<\/p>\n

 <\/p>\n

Acceleration<\/h4>\n

Labor inefficiency problems are further compounded if the project\u2019s completion date is \u201ccarved in stone.\u201d For each hour lost due to a lack of coordination, an hour must be recovered somewhere during the period of construction. Typically, the contractor has already scheduled its available crews for full-time work. Consequently, acceleration often requires the contractor to either pay overtime or hire additional help.<\/p>\n

The acceleration of work will also lead to other substantial, but more inconspicuous, costs for the contractor. An accelerated, or compressed, project schedule forces the contractor to complete the same amount of work in a shorter period of time. As a result, the work of project contractors begins to overlap. This condition, called \u201ctrade stacking,\u201d can dramatically affect labor productivity. In such circumstances, crews sit idle awaiting the completion of work which must precede their own. Further, necessary work space is limited by extra bodies, equipment, and materials. Stacking of trades becomes both a productivity and safety concern for the contractor.<\/p>\n

Loss of worker productivity due to prolonged overtime is another unavoidable side-effect of acceleration. A job which one person can complete in two weeks at fifty hours per week cannot necessarily be performed in one week if the same person works one hundred hours. Labor performance and efficiency rates typically drop during periods of prolonged overtime. In fact, a study conducted by the Business Roundtable Construction Industry Cost Effectiveness Task Force revealed that a construction worker working fifty (50) hours per week for ten weeks is only 75% as productive per hour as a worker working forty (40) hours per week. The study also determined that if a construction worker works seventy (70) hours per week for ten weeks, the worker\u2019s productivity rate shrinks to 50%. The obvious, but seemingly illogical, conclusion is that the worker performing forty (40) hours of work per week is actually more productive than the worker performing seventy (70) hours of work per week. In other words, the accelerating contractor relying on prolonged overtime may actually be paying its workers more money to produce less work.<\/p>\n

 <\/p>\n

Conclusion<\/span><\/h1>\n

When involved in a multi-prime contract plagued with coordination problems, the contractor should review its contract to ascertain its coordination responsibilities thereunder. If the contract contains language shifting coordination responsibilities from the owner to the contractor, the contractor must work with its fellow prime contractors to improve project coordination. If such efforts prove futile, the contractor can demand that the owner act on its contractual duty to compel the cooperation of the other prime contractors. Should the owner refuse to demand such cooperation, the contractor may possess a valid claim against the owner for any increased costs relating to labor inefficiencies and acceleration.<\/p>\n

 <\/p>\n

This discussion is generalized in nature and should not be considered a substitute for professional advice. \u00a9 FWH&T<\/em><\/p>\n","protected":false},"excerpt":{"rendered":"

Introduction Traditionally, on large construction projects, an owner contracted with a general contractor for the construction of the entire project. The owner had a single contract with the general contractor. As a result,\u2026<\/p>\n","protected":false},"author":7,"featured_media":0,"comment_status":"closed","ping_status":"closed","sticky":false,"template":"","format":"standard","meta":{"_acf_changed":false,"footnotes":""},"categories":[7],"tags":[],"class_list":["post-635","post","type-post","status-publish","format-standard","hentry","category-briefing-papers"],"acf":[],"yoast_head":"\nCoordination of Multi-Prime Contracts - Fabyanske, Westra, Hart & Thomson<\/title>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Coordination of Multi-Prime Contracts - Fabyanske, Westra, Hart & Thomson\" \/>\n<meta property=\"og:description\" content=\"Introduction Traditionally, on large construction projects, an owner contracted with a general contractor for the construction of the entire project. The owner had a single contract with the general contractor. As a result,\u2026\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/\" \/>\n<meta property=\"og:site_name\" content=\"Fabyanske, Westra, Hart & Thomson\" \/>\n<meta property=\"article:published_time\" content=\"1999-11-01T15:38:15+00:00\" \/>\n<meta name=\"author\" content=\"Eric Campbell\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"Eric Campbell\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"10 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/\",\"url\":\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/\",\"name\":\"Coordination of Multi-Prime Contracts - Fabyanske, Westra, Hart & Thomson\",\"isPartOf\":{\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/#website\"},\"datePublished\":\"1999-11-01T15:38:15+00:00\",\"dateModified\":\"1999-11-01T15:38:15+00:00\",\"author\":{\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/#\/schema\/person\/0f597b4f28d75111b5b0b3c5e7d4f66e\"},\"breadcrumb\":{\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/#breadcrumb\"},\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/\"]}]},{\"@type\":\"BreadcrumbList\",\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/#breadcrumb\",\"itemListElement\":[{\"@type\":\"ListItem\",\"position\":1,\"name\":\"Home\",\"item\":\"https:\/\/www.fwhtlaw.com\/blog\/\"},{\"@type\":\"ListItem\",\"position\":2,\"name\":\"Coordination of Multi-Prime Contracts\"}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/#website\",\"url\":\"https:\/\/www.fwhtlaw.com\/blog\/\",\"name\":\"Fabyanske, Westra, Hart & Thomson\",\"description\":\"Twin Cities Law Firm | Business Attorneys\",\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.fwhtlaw.com\/blog\/?s={search_term_string}\"},\"query-input\":\"required name=search_term_string\"}],\"inLanguage\":\"en-US\"},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/#\/schema\/person\/0f597b4f28d75111b5b0b3c5e7d4f66e\",\"name\":\"Eric Campbell\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.fwhtlaw.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/d32e03f714794dbae88ed41b83264cedb41953bb8092ae9e82bb752fd59d0686?s=96&d=mm&r=g\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/d32e03f714794dbae88ed41b83264cedb41953bb8092ae9e82bb752fd59d0686?s=96&d=mm&r=g\",\"caption\":\"Eric Campbell\"},\"url\":\"https:\/\/www.fwhtlaw.com\/blog\/author\/ecampbellfwhtlaw-com\/\"}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Coordination of Multi-Prime Contracts - Fabyanske, Westra, Hart & Thomson","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/","og_locale":"en_US","og_type":"article","og_title":"Coordination of Multi-Prime Contracts - Fabyanske, Westra, Hart & Thomson","og_description":"Introduction Traditionally, on large construction projects, an owner contracted with a general contractor for the construction of the entire project. The owner had a single contract with the general contractor. As a result,\u2026","og_url":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/","og_site_name":"Fabyanske, Westra, Hart & Thomson","article_published_time":"1999-11-01T15:38:15+00:00","author":"Eric Campbell","twitter_card":"summary_large_image","twitter_misc":{"Written by":"Eric Campbell","Est. reading time":"10 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"WebPage","@id":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/","url":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/","name":"Coordination of Multi-Prime Contracts - Fabyanske, Westra, Hart & Thomson","isPartOf":{"@id":"https:\/\/www.fwhtlaw.com\/blog\/#website"},"datePublished":"1999-11-01T15:38:15+00:00","dateModified":"1999-11-01T15:38:15+00:00","author":{"@id":"https:\/\/www.fwhtlaw.com\/blog\/#\/schema\/person\/0f597b4f28d75111b5b0b3c5e7d4f66e"},"breadcrumb":{"@id":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/#breadcrumb"},"inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/"]}]},{"@type":"BreadcrumbList","@id":"https:\/\/www.fwhtlaw.com\/blog\/1999\/11\/01\/coordination-multi-prime-contracts\/#breadcrumb","itemListElement":[{"@type":"ListItem","position":1,"name":"Home","item":"https:\/\/www.fwhtlaw.com\/blog\/"},{"@type":"ListItem","position":2,"name":"Coordination of Multi-Prime Contracts"}]},{"@type":"WebSite","@id":"https:\/\/www.fwhtlaw.com\/blog\/#website","url":"https:\/\/www.fwhtlaw.com\/blog\/","name":"Fabyanske, Westra, Hart & Thomson","description":"Twin Cities Law Firm | Business Attorneys","potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.fwhtlaw.com\/blog\/?s={search_term_string}"},"query-input":"required name=search_term_string"}],"inLanguage":"en-US"},{"@type":"Person","@id":"https:\/\/www.fwhtlaw.com\/blog\/#\/schema\/person\/0f597b4f28d75111b5b0b3c5e7d4f66e","name":"Eric Campbell","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.fwhtlaw.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/d32e03f714794dbae88ed41b83264cedb41953bb8092ae9e82bb752fd59d0686?s=96&d=mm&r=g","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/d32e03f714794dbae88ed41b83264cedb41953bb8092ae9e82bb752fd59d0686?s=96&d=mm&r=g","caption":"Eric Campbell"},"url":"https:\/\/www.fwhtlaw.com\/blog\/author\/ecampbellfwhtlaw-com\/"}]}},"_links":{"self":[{"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/posts\/635","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/users\/7"}],"replies":[{"embeddable":true,"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/comments?post=635"}],"version-history":[{"count":1,"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/posts\/635\/revisions"}],"predecessor-version":[{"id":4369,"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/posts\/635\/revisions\/4369"}],"wp:attachment":[{"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/media?parent=635"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/categories?post=635"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.fwhtlaw.com\/blog\/wp-json\/wp\/v2\/tags?post=635"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}